Office Blind Systems - Confirm Your Order

Please use the form below to confirm your order.
(Information required to complete this form can be viewed on your estimate/quote)

Please Note: By submitting this form you are confirming a legal and binding contract subject
to our terms and conditions. This form should only be submitted by those who have the
authority to confirm such orders for and on behalf of your company/organisation.

* Required.

* Company/Organisation:
* Contact Name:
* Email Address:
* Telephone:
* Your Purchase Order No./Ref:
* Quote/Estimate Date:
* Quote/Estimate No.:
* Job Ref No. (If Stated):
* Account No. (If Stated):
* Total Order Value (Incl VAT):
* Special Instructions:

Your Agreement and Order Confirmation (Please tick box below)

Terms and Conditions

1. DEFINITIONS 
  
1.1 "Buyer" means the individual, company or organisation who buys or agrees to buy the Goods from the Seller;  
  
1.2 "Consumer" shall have the meaning ascribed in section 12 of the Unfair Contract Terms Act 1977;  
  
1.3 "Contract" means the contract between the Seller and the Buyer for the sale and purchase of Goods incorporating these Terms and Conditions;  
  
1.4 Goods" means the articles that the Buyer agrees to buy from the Seller; 
 
  
1.5 "Seller" means Office Blind Systems Limited, Unit 6, 99a Station Road, London E4 7BU United Kingdom;  
  
1.6 "Terms and Conditions" means the terms and conditions of sale set out in this document and any special terms and conditions agreed in writing by the Seller. 
  
2. CONDITIONS 
  
2.1 Nothing in these Terms and Conditions shall affect the Buyer's statutory rights as a Consumer. 
  
2.2 These Terms and Conditions shall apply to all contracts for the sale of Goods by the Seller to the Buyer and shall prevail over any other documentation or communication from the Buyer. 
  
2.3 Acceptance of delivery/installation of the Goods shall be deemed conclusive evidence of the Buyer's acceptance of these Terms and Conditions. 
  
2.4 Any variation to these Terms and Conditions (including any special terms and conditions agreed between the parties) shall be inapplicable unless agreed in writing by the Seller. 
  
3. ORDERING 
  
3.1 All orders for Goods shall be deemed to be an offer by the Buyer to purchase Goods pursuant to these Terms and Conditions and are subject to acceptance by the Seller. The Seller may choose not to accept an order for any reason. 
  
3.2 Where the Goods ordered by the Buyer are not available from stock the Buyer shall be notified and given the option to either wait until the Goods are available from stock. 
  
4. PRICE AND PAYMENT 
  
4.1 The Price of the Goods shall be that stipulated on the Seller's Estimate/Quote. The Price includes delivery charges if delivered and installation charges if required within the London M25 radius and with 10 radius outside the London M25 area. Additional delivery and/or installation charges are payable if delivery is outside the prescribed area. 
  
4.2 The total purchase price, including VAT and delivery and/or installation charges, if any, will be displayed in the Estimate prior to confirming the order.  
  
4.3 Payment of the Price plus VAT and delivery and/or installation charges must be made in full once the Goods have been taken, picked up, despatched, delivered or installed Unless the privilege of a pre-arranged credit account of maximum 28 days net has been agreed and arranged. 
  
5. RIGHTS OF SELLER 
  
5.1 The Seller reserves the right to adjust the price and specification of any item at its discretion. 
  
5.2 The Seller reserves the right to withdraw any goods from the range available at any time. 
  
5.3 The Seller shall not be liable to anyone for withdrawing any Goods from the range or for refusing to process an order. 
  
6.1 AGE OF CONSENT 
  
6.1 Where Goods may only be purchased by persons of a certain age the Buyer may be asked when placing an order to declare that they are of the appropriate legal age and/or have the authority to purchase the Goods. 
  
6.2 If the Seller discovers that the Buyer is not legally entitled or has the authority to order certain Goods, the Seller shall be entitled to cancel the order immediately, without notice. 
  
7. WARRANTY
The Seller warrants that the Goods will at the time of dispatch correspond to the description given by the Seller. Except where the Buyer is dealing as a Consumer, all other warranties, conditions, or terms relating to fitness for purpose, merchantability or condition of the Goods, whether implied by Statute, common law or otherwise are excluded, and the Buyer is satisfied as to the suitability of the Goods for the Buyer's purpose, not excluding our 1 year guarantee.  
  
8. DELIVERY AND/OR INSTALLATION 
  
8.1 Goods supplied within the UK will normally be delivered within 10 days but please allow 28 working days of receipt/installation of order.  
  
8.2 Goods supplied outside the UK will normally be delivered within 20 days but please allow 38 working days of receipt of order.  
  
8.3 Where a specific delivery date has been agreed, and where this delivery date cannot be met, the Buyer will be notified and given the opportunity to agree a new delivery date. 
  
8.4 The Seller shall use its reasonable endeavors to meet any date agreed for delivery. In any event time of delivery shall not be of the essence and the Seller shall not be liable for any losses, costs, damages or expenses incurred by the Buyer or any third party arising directly or indirectly out of any failure to meet any estimated or agreed delivery date. 
  
8.5 Delivery/Installation of the Goods shall be made to the Buyer's address or the agreed address of installation specified in the order and the Buyer shall make all arrangements necessary to take delivery and to allow reasonable access for installation purposes of the Goods whenever they are tendered for delivery/installation.

8.6 In the case of access for installation the Buyer will ensure that any area where installation is to take place will be fully cleared of, but not limited too, all movable objects, including desks, computers, screens, cables, paperwork, terminals and any object that may cause harm or discomfort to the installation operative(s) the Seller accepts no responsibility whatsoever or howsoever if such areas within 2 metres radius of the installation area is not cleared.

8.7 Title in the Goods shall pass to the Buyer upon full payment of the Goods and risk in the Goods shall pass to the Buyer upon delivery/installaton of the Goods. 
  
9. CANCELLATION AND RETURN 
  
9.1 The Buyer shall inspect the Goods immediately upon delivery/installation and shall notify the Seller within 7 working days of delivery/installation if the Goods are damaged or do not comply with any of the Contract. If the Buyer fails to do so the Buyer shall be deemed to have accepted the Goods. 
  
9.2 Where a claim of defect is made the Goods shall be returned to the Seller for repair/replacement. No refund is offered or implied for custom made Goods. 
  
9.3 Where returned Goods are found to be damaged due to the Buyer's fault the Buyer will be liable for the cost of remedying such damage and/or re-installation charges, call out fee and any other loss. 
  
10. LIMITATION OF LIABILITY 
  
10.1 Except as may be implied by law where the Buyer is dealing as a Consumer, in the event of any breach of these Terms and Conditions by the Seller the remedies of the Buyer shall be limited to damages which shall in no circumstances exceed the Price of the Goods and the Seller shall under no circumstances be liable for any indirect, incidental or consequential loss or damage whatever. 
  
10.2 Nothing in these Terms and Conditions shall exclude or limit the liability of the Seller for death or personal injury resulting from the negligence of the Seller or that of the Seller's agents or employees. 
  
11. WAIVER
No waiver by the Seller (whether express or implied) in enforcing any of its rights under this contract shall prejudice its rights to do so in the future.  
  
12. FORCE MAJEURE
The Seller shall not be liable for any delay or failure to perform any of its obligations if the delay or failure results from events or circumstances outside its reasonable control, including but not limited to acts of God, strikes, lock outs, accidents, war, fire, breakdown of plant or machinery or shortage or unavailability of raw materials from a natural source of supply, and the Seller shall be entitled to a reasonable extension of its obligations.  
  
13. SEVERANCE
If any term or provision of these Terms and Conditions is held invalid, illegal or unenforceable for any reason by any court of competent jurisdiction such provision shall be severed and the remainder of the provisions hereof shall continue in full force and effect as if these Terms and Conditions had been agreed with the invalid illegal or unenforceable provision eliminated.  
  
14. CHANGES TO TERMS AND CONDITIONS
The Seller shall be entitled to alter these Terms and Conditions at any time. but this right shall not affect the existing Terms and Conditions accepted by the Buyer upon making a purchase.  
  
15. GOVERNING LAW AND JURISDICTION
These Terms and Conditions shall be governed by and construed in accordance with the law of England and the parties hereby submit to the exclusive jurisdiction of the English courts.

* I/We agree to all the Terms and Conditions. Tick to Agree